Terms of Service

C&S Construction
Phone: (903) 307-4386
Email: [email protected]
Address: 1324 Hillcrest, Sulphur Springs, TX 75482

Effective Date: December 18, 2025

These Terms of Service ("Terms") govern your use of C&S Construction’s website, communications, and services (collectively, the "Services"). By contacting us, requesting an estimate, signing a proposal or contract, opting in to communications, or otherwise using our Services, you agree to these Terms.

SMS/Text Messaging Use Cases

If you opt in to receive SMS or MMS text messages from C&S Construction, we may use text messaging to communicate with you about estimates, scheduling, your project, and our services. Text messages may include:

Estimate communications, including request confirmations, follow-ups, clarifying questions, and quote delivery

Scheduling and appointment coordination, including site visits, start dates, crew arrival windows, reschedules, and cancellations

Project updates, including milestones, progress notes, change order confirmations, material delays, and completion updates

Account and billing notices, including invoices, payment reminders, receipts, and balance confirmations

Customer support and two-way messaging, including answering questions, collecting details or photos, and handling service requests

Safety and urgent notifications, including weather delays, site access issues, and other time-sensitive updates

Promotional messages, including special offers, seasonal promotions, new services, and limited-time deals, but only if you have opted in to receive them

Carrier liability disclaimer. Carriers are not responsible for delayed, failed, undelivered, or misdirected delivery of any SMS or MMS messages and are not liable for any issues related to message transmission or delivery.

Message frequency and fees. Message frequency may vary. Standard message and data rates may apply.

Opt-out and help. You can opt out at any time by replying STOP. You can request help by replying HELP.

Age restriction (18+). By opting in to receive text messages from C&S Construction, you represent and warrant that you are at least 18 years old, or that a parent or legal guardian has provided consent on your behalf where permitted by applicable law.

Messaging Consent Message (SMS Opt-In)

By providing your phone number and submitting a form on this website, you consent to receive text messages from C&S Construction related to scheduling, appointment reminders, estimates, project updates, and customer support. Message frequency may vary. You can opt out at any time by replying STOP. For help, reply HELP.

Messaging and Data Rates Disclosure

Message and data rates may apply to any text messages sent or received as part of communications with C&S Construction, depending on your mobile carrier plan. Carriers are not liable for delayed or undelivered messages. Message frequency may vary.

Opt-Out: You may opt out of SMS messages at any time by replying STOP. After you send STOP, you may receive one final message confirming your opt-out.

Help: For help, reply HELP or contact C&S Construction through the contact information listed on this website.

Supported Carriers: SMS services may not be available on all carriers or supported on all devices.

Privacy: Your consent to receive text messages is not a condition of purchase. We do not sell your personal information. For more information on how we handle your data, please review our Privacy Policy.

1. Definitions

"Company," "we," "us," and "our" refer to C&S Construction.

"Client," "you," and "your" refer to the person or entity requesting or receiving Services.

"Project" means the work described in a written estimate, proposal, scope of work, work order, or contract.

2. Scope of Services

We provide construction-related services, which may include, but are not limited to, remodeling, additions, barndominiums, repairs, and related labor and material coordination. Specific deliverables, materials, timelines, and pricing must be confirmed in writing.

Any drawings, measurements, photos, or descriptions you provide may be relied upon for estimates and planning. You are responsible for providing accurate and complete information.

3. Estimates, Proposals, and Changes

Estimates are non-binding until accepted in writing and may be subject to change due to site conditions, material availability, price changes, or scope adjustments.

Change Orders: Any change to the Project scope, materials, design, schedule, or site conditions may require a written change order and may affect price and completion time. We are not obligated to perform changes without written approval.

4. Scheduling and Delays

Project start dates and completion timelines are estimates unless expressly stated as guaranteed in writing.

Delays can occur due to factors outside our control, including permitting timelines, inspections, weather, material or labor availability, concealed conditions, homeowner decisions, or third-party vendors. C&S Construction is not liable for delays caused by these factors.

5. Permits, Approvals, and Utilities

Unless stated otherwise in writing:

You are responsible for ensuring the Project is permitted or approved as required by local authorities and homeowner associations

If we agree in writing to obtain permits, permit costs and related fees are the Client’s responsibility unless included in the contract price

You agree to provide safe access to the jobsite, working utilities such as water and electricity, and a reasonably clear work area

6. Site Conditions, Access, and Safety

You agree to provide:

Access to the property during agreed working hours

Disclosure of known hazards, such as asbestos, mold, structural issues, buried lines, or septic systems

A safe environment for our crew, subcontractors, and visitors

We may pause work if we determine conditions are unsafe or if necessary information is withheld.

7. Materials and Substitutions

Material selections, brands, colors, and finishes should be confirmed in writing. If a specified material is discontinued, backordered, or unavailable, we may propose a reasonable substitute. Price differences may be addressed through a change order.

8. Payments

Payment terms are defined in your written agreement, estimate, invoice, contract, or proposal. Unless otherwise stated in writing:

Deposits may be required to schedule labor and order materials

Progress payments may be due at milestones

Final payment is due upon substantial completion or as stated in the contract

Unpaid balances may result in work stoppage, rescheduling, late fees if permitted by law, and collection efforts.

9. Cancellations and Work Stoppage

If you cancel a Project after acceptance or after work or material ordering has begun, you are responsible for:

Work performed to date

Materials ordered or delivered

Restocking fees

Reasonable administrative costs

If the Project is paused due to Client delay, including selections not being made, access not being provided, or non-payment, the schedule may be reset and additional costs may apply.

10. Inspections, Punch Lists, and Acceptance

You agree to conduct a walk-through when requested. Minor touch-ups and completion items may be listed in a punch list. Final payment remains due as stated in the agreement, even if minor punch list items remain, unless your written contract states otherwise.

11. Warranty

If we provide a workmanship warranty, the terms and duration will be stated in writing. Unless otherwise stated:

Warranty coverage does not include normal wear and tear, abuse, improper maintenance, damage caused by others, Acts of God, or issues resulting from materials provided by the Client

Manufacturer warranties, if any, apply to products and materials and are governed by the manufacturer’s terms

To request warranty service, contact us at [email protected] with photos and a description of the issue.

12. Client Responsibilities

You agree to:

Make timely decisions on selections and approvals

Keep pets, children, and non-essential visitors away from work zones

Remove or protect valuables in and around the jobsite

Maintain adequate property insurance

13. Photos, Marketing, and Reviews

We may take before-and-after photos or videos of Projects for documentation, quality control, and training. With your permission, whether written or provided through clear confirmation, we may use non-identifying images for marketing, including on our website, social media, or portfolio. You may opt out at any time by emailing us.

14. Communications (Calls, Texts, Email)

By contacting us, you consent to receive communications related to estimates, scheduling, and your Project via phone, text message, or email. Message and data rates may apply where applicable. You can opt out of promotional texts at any time by replying STOP, if applicable, or by emailing us.

15. Limitation of Liability

To the maximum extent permitted by law:

C&S Construction is not liable for indirect, incidental, special, consequential, or punitive damages

Our total liability for any claim related to the Services will not exceed the amount you paid us for the portion of Services giving rise to the claim

Some states do not allow certain limitations, so these limitations may not fully apply to you.

16. Dispute Resolution

If a dispute arises, you agree to first contact us to attempt resolution in good faith. If not resolved, disputes will be handled in accordance with applicable Texas law, and venue will be in a court of competent jurisdiction in Texas, unless otherwise required by law or agreed in writing.

17. Right to Refuse or Terminate Service

We may refuse or terminate Services if:

The jobsite is unsafe

You fail to pay according to the agreement

There is harassment, threats, or abusive conduct toward our team

You request work that violates code, law, or safety standards

18. Website Use

If you use our website:

Content is provided for general information and may change without notice

You agree not to misuse the site, including spam, hacking, scraping, or unlawful activity

Intellectual property, including logos, text, and photos, belongs to C&S Construction unless otherwise stated

19. Changes to These Terms

We may update these Terms periodically. Updated Terms become effective when posted or otherwise provided. For active Projects, the signed written agreement governs in the event of conflict.

Please also review our Privacy Policy.

20. Contact

C&S Construction
1324 Hillcrest
Sulphur Springs, TX 75482
(903) 307-4386
[email protected]